Legals March 3, 2020

INVITATION TO BID AIRPORT IMPROVEMENTS LIBBY, MONTANA Notice is hereby given that sealed bids will be received and publicly opened at 10:00 a.m., local time on Wednesday, March 18, 2020, by the Lincoln County Commission at the Lincoln County Commissioners' Office, North Lincoln County Annex, Door 5, 52 Highway 37 North, P.O. Box 2012, Eureka, MT 59917, for the following "Airport Improvement" to include: ACQUISITION OF SNOW REMOVAL EQUIPMENT ALL WHEEL DRIVE SNOW PLOW TRUCK WITH 14'BLADE Bids must be sealed and delivered to the Lincoln County Commissioners' Office, North Lincoln County Annex, Door 5, 52 Highway 37 North, P.O. Box 2012, Eureka, MT 59917 at or before 10:00 a.m., local time on Wednesday, March, 18, 2020, and marked "Bid for Snow Removal Equipment at the Libby Airport, AIP 3-30-0049-014-2020." The bidder's name, address and state Contractor's Registration number shall appear on the envelope. All bids must be accompanied by lawful monies of the United States or a Cashier's Check, a Certified Check, Bid Bond, Bank Money Order or Bank Draft, drawn and issued by a National Banking Association located in the State of Montana, or by any Banking Corporation incorporated under the Laws of the State of Montana, in an amount equal to not less than ten (10) percent of the amount of the base bid, payable to the order of the Lincoln County Airport Commission as liquidated damages in the event said successful bidder shall fail or refuse to execute the contract in accordance with the terms of his bid. Complete electronic Project Specifications, and Bid Proposal Packet are available on the Morrison-Maierle, Inc. website "www.m-m.net", scroll down and click on the "Project Bidding" banner, follow the link, "Browse Projects" as needed, and select this project from the project list. Documents can only be viewed on the Morrison-Maierle, Inc. website, and cannot be downloaded or printed without purchasing. To purchase and download the project documents in pdf format, click "Download Project PDF" and sign on to QuestCDN.com or join for a free membership. Plan documents can be downloaded for a fee of $30. Please contact QuestCDN at 952-233-1632 or email "info@questcdn.com" for assistance in the free membership registration, downloading, and working with this digital project information. The Owner reserves the right to reject any or all bids and to waive informalities or irregularities in any bid. The Bidder must supply all the information required by the bid documents and specifications. Funding for This Contract is Federally Assisted. Contractors at every tier must comply with applicable federal requirements including but not limited to: the Buy American Preference, Foreign Trade Restriction, Affirmative Action, Government wide Debarment and Suspension, Government wide Requirements for Drug-free Workplace, and Procurement of Recovered Materials, as contained in the bid documents. This contract will be funded in part by a grant from the Federal Aviation Administration. Therefore, award of the Contract by the Sponsor will be made subject to concurrence of FAA. Bidders may not withdraw Proposals for a period of ninety (90) days after the bid opening date. Signed: /s/ Mark Peck Chairman, Lincoln County Airport Board Published In The Western News February 28, March 6, & 13, 2020. MNAXLP

The Montana Department of Revenue, Alcoholic Beverage Control Division, announces the availability of one (1) new original Montana Retail On-Premises Restaurant Beer and Wine License for the Eureka quota area as a result of the Montana legislative change separating the combined quota area of Eureka/Rexford. The Montana Alcoholic Beverage Code (Title 16 of the Montana Code Annotated) requires each incorporated city to have their own designated quota area and requires the department to conduct a competitive bidding process for available licenses. The available Montana Retail On-Premises Consumption Restaurant Beer and Wine License for the Eureka quota area may be located within the corporate limits of Eureka or within 5 miles of Eureka's corporate limits. A map of the Eureka quota area can be located at mtrevenue.gov This license is not eligible to offer gambling under Title 23, chapter 5, part 3, 5, or 6. To enter the competitive bidding process, the individual or business entity must submit electronically a competitive bid form that includes your bid amount, an irrevocable letter of credit for at least the bid amount from a financial institution naming the department as the beneficiary and pay a $100 non-refundable processing fee and any associated payment processing fees. The competitive bid form can be found at myrevenue.mt.gov The minimum bid for this license is set at $13,125. The competitive bidding process closes on March 8, 2020 at midnight Mountain Standard Time. The highest successful bidder will be notified by the department. The successful bidder must submit an application for licensure within 60 days. Questions? Contact (406) 444-6900 Published In The Western News February 11, 18, 25, & March 3, 2020. MNAXLP

RUSSELL S. BARNES Attorney for Plaintiff 503 California Ave. Libby, MT 5992 MATTHEW J. CUFFE DISTRICT JUDGE THE DISTRICT COURT OF THE NINETEENTH JUDICIAL DISTRICT OF THE STATE OF MONTANA, IN AND FOR THE COUNTY OF LINCOLN IN THE MATTER OF LINCOLN COUNTY SHELTERED WORKSHOP Plaintiff, -vs- THE PROPANE COMPANY, A MONTANA CORPORATION, and all other persons, unknown, claiming or who might claim any right, title, estate or interest in, or lien or encumbrance upon the real property described in the Complaint, or any thereof adverse to Plaintiffs' title thereto, whether such claim or possible claim be present or contingent, including any claim or possible claim of dower, inchoate or accrued, Defendant. DV-19-218 S U M M O N S THE STATE OF MONTANA TO THE ABOVE NAMED DEFENDANT You are hereby summoned to answer the Complaint in the action, which is filed in the office of the Clerk of this Court, a copy of which is herewith served upon you, and to file your Answer and serve a copy thereof upon the Plaintiffs' attorney within twenty (20) days after the service of this Summons, exclusive of the day of service, and in case of your failure to appear or answer, judgment will be taken against you by default, for the relief demanded in the Complaint. This action is brought for the purpose of quieting title to the land situated in Lincoln County, Montana, and described in the Complaint. WITNESS MY HAND AND THE SEAL OF THIS COURT THIS 28th day of October, 2019. s/s Tricia Brooks CLERK OF DISTRICT COURT By s/s Kelsi Chambers Deputy Clerk Published In The Western News February 25, March 3, 10, 2020. MNAXLP

RUSSELL S. BARNES Attorney for Plaintiff 503 California Ave. Libby, MT 5992 MATTHEW J. CUFFE DISTRICT JUDGE IN THE DISTRICT COURT OF THE NINETEENTH JUDICIAL DISTRICT OF THE STATE OF MONTANA, IN AND FOR THE COUNTY OF LINCOLN NO-DV-19-211 IN THE MATTER OF LINCOLN COUNTY SHELTERED WORKSHOP Plaintiff, -vs- WALTER H. KEMP, and all other persons, unknown, claiming or who might claim any right, title, estate or interest in, or lien or encumbrance upon the real property described in the Complaint, or any thereof adverse to Plaintiffs' title thereto, whether such claim or possible claim be present or contingent, including any claim or possible claim of dower, inchoate or accrued, Defendant. S U M M O N S THE STATE OF MONTANA TO THE ABOVE NAMED DEFENDANT You are hereby summoned to answer the Complaint in the action, which is filed in the office of the Clerk of this Court, a copy of which is herewith served upon you, and to file your Answer and serve a copy thereof upon the Plaintiffs' attorney within twenty (20) days after the service of this Summons, exclusive of the day of service, and in case of your failure to appear or answer, judgment will be taken against you by default, for the relief demanded in the Complaint. This action is brought for the purpose of quieting title to the land situated in Lincoln County, Montana, and described in the Complaint. WITNESS MY HAND AND THE SEAL OF THIS COURT THIS 28th day of October, 2020. s/s TRICIA BROOKS CLERK OF DISTRICT COURT By s/s Kelsi Chambers Deputy Clerk Published In The Western News February 25, March 3 & 10, 2020. MNAXLP